Website Design Contract
This Website Design Contract (the "Agreement") is entered into on 2024-01-01 (the "Effective Date") by and between Client Name ("Client") with an address of 123 Client St and Designer Name ("Designer") with an address of 456 Designer Rd.
1. Project Overview
Website Type: Business Website (business website, e-commerce, portfolio, blog, landing page, web app, etc.)
Primary Purpose: Company Information and Lead Generation
Target Audience: Business Professionals
Current Website: New Site (redesign / new site)
Domain Name: example.com
Estimated Page Count: 10 pages
Desired Launch Date: target launch
2. Scope of Work and Deliverables
Design Services:
- Discovery and planning session
- Sitemap and information architecture
- Wireframes: wireframe details
- Visual design mockups: design mockup count unique page templates
- Responsive design for: responsive breakpoints (desktop, tablet, mobile)
- Style guide/brand guidelines
- additional design services
Development Services:
- HTML/CSS coding
- JavaScript functionality
- CMS integration: cms platform (WordPress, Webflow, Shopify, custom, etc.)
- Contact forms: form count forms
- Blog setup: blog included
- Search functionality: search included
- additional dev services
E-Commerce Features (if applicable):
- Shopping cart integration
- Payment gateway setup: payment gateways
- Product catalog: product count products initially
- Inventory management
- Shipping calculator
- ecommerce features
Technical Features:
- SEO optimization (on-page)
- Google Analytics integration
- Social media integration
- SSL certificate installation
- Performance optimization
- Security measures
- GDPR/privacy compliance: compliance requirements
- technical features
Third-Party Integrations:
- Email marketing: email integration
- CRM: crm integration
- Booking/scheduling: booking system
- Live chat: chat integration
- other integrations
Content Services:
- Copywriting: copywriting included (Client provides / Designer writes / combination)
- Image sourcing: image sourcing (Client provides / stock photos included / professional photography arranged)
- Content upload: content upload (up to initial pages pages)
Deliverables:
- Fully functional responsive website
- Source files (PSD, Sketch, Figma, etc.): source files
- Documentation: documentation included
- Training: training included (training hours hours)
- revision rounds rounds of revisions per phase
Services NOT Included:
- Ongoing maintenance after launch
- Hosting fees
- Domain registration/renewal
- Third-party plugin/software licenses
- Professional photography/videography
- Ongoing SEO/marketing
- excluded services
3. Project Phases and Timeline
Project Start Date: project start
Estimated Completion: total weeks weeks from start
Phase 1: Discovery & Planning (phase1 weeks weeks)
- Kickoff meeting
- Requirements gathering
- Sitemap approval
- Competitor research
- Milestone payment: phase1 payment
Phase 2: Design (phase2 weeks weeks)
- Wireframes
- Initial design concepts: design concepts options
- Design revisions: design revisions rounds
- Final design approval
- Milestone payment: phase2 payment
Phase 3: Development (phase3 weeks weeks)
- Front-end development
- Back-end/CMS development
- Feature implementation
- Content population
- Milestone payment: phase3 payment
Phase 4: Testing & Launch (phase4 weeks weeks)
- Quality assurance testing
- Browser compatibility testing: browser support
- Mobile responsiveness testing
- Client review and feedback
- Revisions
- DNS/hosting setup assistance
- Launch
- Final payment: final payment
Timeline Contingencies: Dates are estimates subject to:
- Timely Client feedback and content provision
- No major scope changes
- Third-party service availability
- Hosting/domain access
4. Client Responsibilities
Client agrees to provide:
- Timely feedback on deliverables (within feedback days business days)
- All content (text, images, videos) by content deadline
- Brand assets (logos, fonts, colors)
- Access to hosting, domain, and necessary accounts
- Login credentials for existing systems
- Feedback and approvals according to schedule
- Payment according to schedule
- Final content approval before launch
- additional client responsibilities
Content Format: content format requirements
Client Delays: Project timeline extended if Client delays providing materials or feedback beyond delay threshold days
5. Revisions and Changes
Included Revisions: revision rounds rounds per phase
Revision Scope: Minor adjustments to approved concepts (color changes, text edits, layout tweaks)
Major Changes: Significant departures from approved direction require new proposal and pricing
Additional Revisions: Beyond included rounds: additional revision rate per hour
Change Order Process:
- Client submits written change request
- Designer provides time/cost estimate within estimate days days
- Client approves
- Change Order signed
- Timeline and payment adjusted
Scope Creep Prevention: Features not in original scope require Change Order
6. Testing and Browser Compatibility
Browser Support:
- Chrome (latest 2 versions)
- Firefox (latest 2 versions)
- Safari (latest 2 versions)
- Edge (latest 2 versions)
- additional browsers
Device Testing:
- Desktop (1920px+, 1366px, 1024px)
- Tablet (768px)
- Mobile (375px, 414px)
- additional devices
Accessibility: accessibility standards (WCAG 2.1 Level AA / basic / not specified)
Performance Targets:
- Page load time: Under load time seconds seconds
- Mobile speed score: mobile speed target
- performance requirements
7. Hosting and Domain
Hosting: hosting arrangement (Client provides / Designer arranges / Designer provides)
Hosting Requirements: hosting specs
Domain Registration: domain responsibility
DNS Management: dns management
Email Setup: email setup (included / additional fee / not included)
SSL Certificate: ssl arrangement (included / Client obtains / hosting provider)
Ongoing Hosting Costs: hosting cost per month (paid by Client directly to host)
8. Compensation and Payment
Total Project Fee: total project fee
Payment Structure:
- Deposit: deposit amount (due upon signing)
- Phase 1 completion: phase1 payment amount
- Phase 2 completion: phase2 payment amount
- Phase 3 completion: phase3 payment amount
- Final launch: final payment amount
Payment Terms: Net payment net days days from invoice
Payment Method: payment methods
Late Payment: late fee or late percentage% per month. Work may be paused after late suspension days days.
Hosting/Licenses: third party costs (Client pays directly / included / billed separately)
Expenses: expense policy (pre-approved only / not applicable)
9. Intellectual Property Rights
Final Work Ownership: Upon full payment, Client owns:
- Custom website design
- Custom code written specifically for project
- Final deliverables
Designer Retains:
- Pre-existing code libraries and frameworks
- Templates and tools
- General techniques and knowledge
Third-Party Components:
- Open-source libraries: Subject to respective licenses
- Premium themes/plugins: premium component licenses
- Stock images: stock image licenses
- Fonts: font licenses
Source Files: source file ownership (provided to Client / retained by Designer / provided for additional fee)
Portfolio Rights: Designer may:
- Display website in portfolio
- Use as case study
- Include screenshots in marketing
- Link to live site
Client may opt out: portfolio opt out
10. Content and Materials
Client-Provided Content: Client warrants ownership or rights to all provided content
Content Liability: Client indemnifies Designer against claims related to Client-provided content
Placeholder Content: Designer may use placeholder text/images during development
Stock Images: stock images included stock images included (if applicable)
Content Migration: Migration of existing content: migration included (up to migration page limit pages)
11. Training and Support
Training Included: training hours hours of training on:
- CMS basics
- Content updates
- Image uploads
- Basic edits
- training topics
Training Format: training delivery (video tutorials / live session / documentation / combination)
Post-Launch Support: support days days of bug fixes and minor adjustments after launch
Support Scope: Fixing defects and issues; does not include new features or content updates
After Support Period: Support available at hourly support rate per hour
12. Maintenance and Updates
Ongoing Maintenance: maintenance offering
If offered:
- Monthly fee: monthly maintenance fee
- Includes: maintenance inclusions
- Updates, backups, security monitoring, minor content changes
Client Self-Maintenance: Client may manage site independently
Designer Not Responsible: For issues caused by:
- Client modifications
- Third-party plugins
- Hosting issues
- Hacking (unless Designer managing security)
13. Warranties and Disclaimers
Designer Warrants:
- Original work (except third-party components)
- No infringement of third-party rights
- Functionality as specified
- Free of material defects for warranty days days
No Guarantee:
- Search engine rankings
- Traffic or conversions
- Specific browser versions beyond listed
- Compatibility with all future updates
Third-Party Services: Designer not responsible for third-party service failures or changes
DISCLAIMER: EXCEPT AS STATED, WEBSITE PROVIDED "AS-IS" WITHOUT WARRANTIES
14. Confidentiality
Confidential Information:
- Business plans and strategies
- Login credentials
- Unpublished designs
- Proprietary information
Protection: Both parties agree to maintain confidentiality
Duration: Survives termination for confidentiality years years
15. Termination
Termination for Convenience: Either party may terminate with termination notice days notice
Upon Termination:
- Client pays for work completed
- Designer delivers work-in-progress
- Kill fee: kill fee if terminated before 50% completion
Termination for Cause:
- Material breach not cured within cure days days
- Non-payment
- Abandonment
16. Limitation of Liability
Liability Cap: Designer's liability limited to liability limit (typically total fees paid)
No Consequential Damages: Designer not liable for lost profits, data loss, or business interruption
17. Indemnification
Client Indemnifies Designer: Against claims from Client-provided content or materials
Designer Indemnifies Client: Against claims from Designer's original work infringing third-party rights
18. Dispute Resolution
Governing Law: Laws of governing jurisdiction
Dispute Process:
- Good faith negotiation
- Mediation
- arbitration or litigation
Attorney Fees: Prevailing party entitled to reasonable fees
19. General Provisions
Entire Agreement: Supersedes all prior agreements
Amendments: Must be in writing
Independent Contractor: Designer is independent contractor
Assignment: Neither party may assign without consent
Severability: Invalid provisions don't affect remainder
Force Majeure: Neither party liable for delays beyond control
20. Contact Information
Client: Primary Contact: client contact Email: client email Phone: client phone
Designer: Email: designer email Phone: designer phone Website: designer website
21. Signatures
IN WITNESS WHEREOF, the parties have executed this Agreement as of the Effective Date.
Client:
Name: ────────────
Title: ────────────
Signature: ────────────
Date: ────────────
Designer:
Name: ────────────
Title: ────────────
Signature: ────────────
Date: ────────────